Effective Date: 12 May 2024
Welcome to BERG General Contractors By accessing or using our website, berggeneralcontractors.com, and our services, you agree to comply with and be bound by the following Terms and Conditions. Please read them carefully.
By accessing our website or engaging our services, you acknowledge that you have read, understood, and agree to be bound by these Terms and Conditions. If you do not agree with any part of these terms, please do not use our website or services.
Scope of Work:
We offer general contracting services, including but not limited to remodeling, renovations, and construction projects within Broward County and Palm Beach County in Florida and beyond in some cases.
Estimates and Quotes:
All estimates and quotes provided are based on the information available at the time and are subject to change based on project scope and unforeseen conditions.
Payment Terms:
A deposit of percentage amount as defined in the contract of the total project cost is required to begin work.
Progress payments will be outlined in the project agreement and are due as specified in the payment schedule.
Final payment is due upon project completion and client satisfaction.
Methods of Payment:
These will be decided at the time of contract.
Late Payments:
Late payments may incur a fee percentage amount as defined in the contract of the outstanding balance per month.
We reserve the right to suspend work or terminate the contract if payments are not made according to the agreed schedule.
Access and Permissions:
The client is responsible for providing access to the project site and securing necessary permissions and permits unless otherwise agreed upon.
Site Conditions:
The client must disclose any known site conditions that may affect the project, including hazardous materials, structural issues, or utility locations.
Change Orders:
Any changes to the project scope, materials, or specifications must be documented in a written change order, which may result in additional costs and project delays.
Approval Process:
Change orders must be approved in writing by both the client and BERG General Contractors before any additional work is undertaken.
Workmanship Warranty:
We provide a warranty on all workmanship, starting from the date of project completion as and if defined in the contract.
Material Warranty:
Materials are covered by their respective manufacturer‘s warranties. We will assist in the warranty claims process if needed.
Limited Liability:
BERG General Contractors is not liable for any indirect, incidental, or consequential damages arising from the use of our services.
Our total liability for any claims related to our services is limited to the amount paid by the client for those services.
Force Majeure:
We are not liable for delays or failures to perform due to circumstances beyond our control, including but not limited to natural disasters, labor strikes, or supply chain disruptions.
By Client:
The client may terminate the agreement at any time, provided that payment is made for all work completed up to the termination date.
By BERG General Contractors:
We reserve the right to terminate the agreement if the client fails to comply with these Terms and Conditions, including failure to make timely payments.
Governing Law:
These Terms and Conditions are governed by the laws of the State of Florida.
Arbitration:
Any disputes arising from this agreement shall be resolved through binding arbitration as defined in the contract.
Content Ownership:
All content on our website, including text, images, and logos, is the property of BERG General Contractors and is protected by copyright and other intellectual property laws.
Use of Content:
You may not reproduce, distribute, or use any content from our website without our prior written consent.
Please refer to our Privacy Policy for information on how we collect, use, and protect your personal information.
We reserve the right to modify these Terms and Conditions at any time. Any changes will be posted on our website with an updated effective date.
For any questions or concerns regarding these Terms and Conditions, please contact us at:
BERG General Contractors